# M/S SATISH BUILDERS vs UNION OF INDIA

Court: Delhi High Court
Date: 2025-01-10
Citation: O.M.P. (COMM)-267/2019 2025:DHC:135
Petitioner: M/S SATISH BUILDERS
Respondent: UNION OF INDIA

[Official PDF on Delhi High Court website](https://delhihighcourt.nic.in/app/showFileJudgment/JSM10012025OMPCOMM2672019_122843.pdf)

## Judgment text (excerpt)

$~ * IN THE HIGH COURT OF DELHI AT NEW DELHI Judgment reserved on: 30.07.2024 Judgment pronounced on: 10.01.2025 + O.M.P. (COMM) 267/2019 M/S. SATISH BUILDERS .....Petitioner Through: Mr Anshul Mittal, Mr Kshitij Mittal, Ms Vaishali Mittal, Mr Ashok Aggarwal, Mr Sarthak, Advs. versus UNION OF INDIA .....Respondent Through: Mr Manish Mohan, CGSC, Mr Prakhar Vashisth, Mr Deepen Yadav, Mr Shekhar Saharan, Mr Nitish Bhardwaj, Advs. CORAM: HON’BLE MR. JUSTICE JASMEET SINGH JUDGEMENT : JASMEET SINGH, (J) O.M.P (COMM.) NO. 267/2019 1. This is a petition under Section 34 of the Arbitration and Conciliation Act, 1996 (hereinafter called “the Act”) challenging the Award dated 25.01.2019 (hereinafter called the “Impugned Award”) and the Corrected Award dated 18.02.2019 (hereinafter called the “Corrected Impugned Award”) specifically the findings of the learned Arbitrator regarding Claim Nos. 1,2 ,31,32,33,36& 3 in the case titled “Satish Builders Vs. Union of India”. Brief Facts 2. The brief facts in the present matter are as under:- 2013. However, the work was completed on 31.03.2015 (being a total delay of 611 days). c. The Petitioner invoked the Arbitration Clause on 19.05.2017 in terms of

https://niyam.ai/judgements/high-court/2025/january/m-s-satish-builders-vs-union-of-india